(a) The Government may, by written notice to the Contractor, terminate the right of the Contractor, to proceed under this contract if it is found, after notice and hearing, by the Secretary or his duly authorized representative, that gratuities (in the form of entertainment, gifts, or otherwise) were offered or given by the Contractor, or any agent or representative of the Contractor, to any officer or employee of the Government with a view toward securing a contract or securing favorable treatment with respect to the awarding, amending, or the making of any determinations with respect to this contract. (b) In the event that this contract is terminated as provided in paragraph (a) above, the Government shall have the same rights and remedies provided in the clause entitled "Default" in the General Provisions with respect to defaults of the Contractor, and any other rights and remedies provided by law or under this contract. In connection with any discount provided for, time will be computed from date of delivery of the supplies to carrier when delivery and acceptance are at point or origin or from date of delivery at destination or port of embarkation when delivery and acceptance are at either of those points, or from date correct invoice or voucher is received in the office specified by the Government if the latter date is later than the date of delivery. Payment is deemed to be made, for the purpose of earning the discount, on the date of mailing of the Government check. § 6-7.151-9 Requirements clause. The following clause is applicable only to requirements contracts prepared in accordance with § 1-3.405-5(b). REQUIREMENTS CLAUSE (a) The Government agrees to purchase all of its requirements of (specific property or services) for use at (designated activities) during the period from to from the Contractor. The Government shall not, however, be obligated to make any purchases in excess of its actual requirements. (b) The Contractor agrees to furnish up to (maximum delivery obligation) of (specific property or services) while this contract remains in effect. The Contractor shall not, however, be obligated to deliver in excess of (quantity) during any (time) period, nor less than (quantity) in any delivery. (c) Subject to paragraph (b) above, and upon the placing of orders by the Government at least ------ days before the date of requested delivery, the Contractor agrees to make deliveries under this contract at any of the following designated point(s) : (d) The Government shall use a purchase order (Foreign Service Form 455) in making purchases against this contract. § 6-7.151-10 Indefinite quantity clause. The following clause is applicable only to indefinite quantity contracts prepared in accordance with § 1-3.405-5(c). INDEFINITE QUANTITY CLAUSE (a) The Contractor agrees to furnish up to (max. delivery obligation) of (specific property or services) during the period from to to the Government. The Contractor shall not, however, be obligated to deliver in excess of (quantity) during any (time) period, nor less than (quan. tity) in any delivery. (b) Subject to paragraph (a) above, and upon the placing of orders by the Government at least day(s) before the date of requested delivery, the Contractor agrees to make deliveries under this contract at any of the following designated points: (c) The Government agrees to purchase a minimum of (minimum order obligation) of (specific property or services) while this contract is in effect. (d) The Government shall use a purchase order (Foreign Service Form 455) in placing orders against this contract up to the Government's minimum purchase obligation, and in making purchases against this contract over the Government's minimum purchase obligation. § 6-7.151-11 Contracting officer's representative. The following clause may be used in designating an authorized representative of the contracting officer (such a designee may not make any commitments or changes which will affect the price, quality, quantity or delivery terms): REPRESENTATIVES OF CONTRACTING OFFICER The Contracting Officer reserves the right to designate representatives to act for him in furnishing technical guidance and advice or, generally supervise the work to be performed under this contract. Such designation will be in writing and will define the scope and limitations of the designee's authority. A copy of the designation shall be furnished to the contractor. § 6-7.151-12 Labor, supplies and equip ment. LABOR, SUPPLIES AND EQUIPMENT The Contractor shall furnish all labor, supplies, and equipment necessary for the performance of this contract. Necessary storage space for supplies and equipment will be furnished by the Government. § 6-7.151-13 Government property. GOVERNMENT PROPERTY Damage to, or loss of, Government property when it is due to the Contractor's negligence may result in the Contractor being held liable for repair or replacement thereof at the option of the Government. (a) With respect to motor vehicles purchased by the Department of State or the U.S. Information Agency for use by such agencies in foreign countries, the Secretary of the Treasury has granted an exemption from the federal excise tax imposed by 26 U.S.C. 4061(a) provided such vehicles are exported from the United States by such Agencies within a period of 6 months from the date of delivery of such vehicles to the agencies, notwithstanding any use made by such agencies of the vehicles within the United States during the 6-month period. The contract for sale of such vehicles must include a statement to the effect that the sale of the vehicles is made for the exclusive use of the United States and qualifies for the exemption under order of the Secretary of the Treasury dated May 6, 1964 (29 F.R. 6254). The manufacturers must be furnished proof of export within 6 months after the sale. (b) Taxable articles purchased for presentation abroad as gifts to foreign dignitaries and taxable articles purchased for presentation as gifts to foreign dignitaries visiting in the United States but which are almost immediately taken out of the United States may be exempt from any retailers or manufacturers excise taxes in accordance with letter of October 18, 1963 from Chief, Excise Tax Branch, Internal Revenue Service on file in Supply and Transportation Services Division. (c) With respect to purchases from vendors in the United States for export to a Foreign Service Post, the following statement will be included in purchase orders for items subject to excise taxes: This is to certify that the item(s) covered by this purchase order is/are for export solely for the use of the American Foreign Service post shown above. It is, therefore, requested that the extra signed copy of the purchase order furnished herewith be accepted as evidence of intent to export. Final proof of exportation may be obtained from the U.S. Despatch Agent, handling the shipment; such proof to be accepted in lieu of payment of excise tax. [31 F.R. 6624, May 4, 1966] Subpart 6-11.3-State and Local § 6-11.301 Applicability. In certain instances purchases by posts are exempt from various taxes in foreign countries. It is incumbent upon procurement officers to ascertain such exemptions and to take maximum advantage of them. [29 F.R. 12076, Aug. 25, 1964] PART 6-60-CONTRACT APPEAL Sec. AUTHORITY: The provisions of this Part 6-60 issued under sec. 205(c), 63 Stat. 390, as amended, 40 U.S.C. 486(c); sec. 4, 63 Stat. 111, 22 U.S.C. 2658. SOURCE: The provisions of this Part 6-60 contained in Dept. Reg. 108.570, 32 F.R. 15751, Nov. 16, 1967, unless otherwise noted. § 6-60.0 Scope of part. This part relates to disputes arising under Department of State contracts (which shall for the purpose of this part include grants) and to the transfer of certain appellate and review functions of the Department of State to the Armed Services Board of Contract Appeals (referred to in this part as the "ASBCA") and the delegation of authority to ASBCA to hear and decide appeals of contractors from final decisions of contracting officers arising under disputes provisions of contracts awarded by the Department of State. The Armed Services Board of Contract Appeals is designated the authorized representative of the Secretary of State and the Deputy Under Secretary of State for Administration to hear and determine appeals by contractors from final decisions of Contracting Officers on disputed questions arising under Department of State contracts pursuant to provisions of contracts requiring the determination of such appeals by either official or their duly authorized representative. § 6-60.2 Applicability. This designation shall apply to appeals, notice of which is received, after publication in the FEDERAL REGISTER of this revision. § 6-60.3 Department support. The Supply and Transportation Services Division shall ensure support by officers and employees of the Department of State in processing appeals, and ascertaining information to the extent required for that purpose, before the ASBCA and is hereby authorized to require such officers and employees to cooperate for this purpose. § 6-60.4 Rules. (a) In acting under this designation, the ASBCA will follow the rules in 32 CFR 30.1 (Appendix A) Part 2, which are hereby adopted and set forth in paragraph (b) of this section, except as amended. Rule 31 is superseded by the date of effectiveness of this part upon publication. Part 1 of Appendix A, containing the Charter of the ASBCA, is not included in this paragraph. References to military departments and Secretaries thereof are amended to refer to the Department of State and either the Secretary of State or the Deputy Under Secretary of State for Administration, or their duly authorized representative or Board, as appropriate. Amendments, applicable only to appeals arising from Department of State contracts, concerning other provisions of the Rules are identified by the caption (STATE). (b) Part 2-Rules: PREFACE TO RULES OF THE ARMED SERVICES BOARD OF CONTRACT APPEALS 1. SUMMARY OF PERTINENT CHARTER PROVISIONS The Armed Services Board of Contract Appeals is the authorized representative of the Secretary of State, the Deputy Under Secretary of State for Administration, in hearing, considering, and determining as fully and finally as might either official: (a) Appeals by contractors from decisions of contracting officers or their authorized representatives or other authorities on disputed questions, taken pursuant to the provision of contracts requiring the determination of such appeals by the Secretary of State or the Deputy Under Secretary of State for Administration or their duly authorized representative or board; or (b) Appeals by contractors taken pursuant to the provisions of any directive whereby the Secretary of State or the Deputy Under Secretary of State for Administration has granted a right of appeal not contained in the contract. When an appeal is taken pursuant to a Disputes clause in a contract which limits appeals to disputes concerning questions of fact, the Board may in its discretion hear, consider, and decide all questions of law necessary for the complete adjudication of the issue. In the consideration of an appeal, should it appear that a claim is involved which is not cognizable under the terms of the contract, the Board may make findings of fact with respect to such a claim without expressing an opinion on the question of liability. When a contract requires the Secretary of State or the Deputy Under Secretary of State for Administration, personally to render a decision on the matter in dispute, the Armed Services Board of Contract Appeals makes and submits findings and recommendations to the appropriate official with respect thereto. There are a number of divisions of the Armed Services Board of Contract Appeals established by the Chairman of the Board in such manner as to provide for the most effective and expeditious handling of appeals. Appeals are assigned to the divisions for decision without regard to the procuring authority which entered into the contract involved. Hearing may be held by a designated member, or by a duly authorized examiner. The decision of a majority of a division constitutes the decision of the Board provided that the Chairman and two Vice Chairmen jointly signify their approval of the decision. If a majority of the members of a division is unable to agree on a decision, or if the Chairman or one or more of the Vice Chairmen does not signify approval of the decision, determination of the appeal is by the Chairman and Vice Chairmen. A decision by a majority of those individuals then constitutes the decision of the Board. On request of the appellant, an appeal involving $5,000 or less is decided as provided in the Optional Accelerated Procedure set forth in Rule 12 of the Board. II. STATEMENT OF PURPOSE Emphasis is placed upon the sound administration of these rules in specific cases, because it is impracticable to articulate a rule to fit every possible circumstance which may be encountered. These rules will be interpreted so as to secure just and inexpensive determination of appeals without unnecessary delay. Preliminary procedures are available to encourage full disclosure of relevant and material facts and to discourage unwarranted surprise. All time limitations specified for various procedural actions are computed as maximums, and are not to be fully exhausted if the action described can be accomplished in a lesser period. These time limitations are similarly eligible for extension in appropriate circumstances, on good cause shown. Whenever reference is made to contractor, appellant, contracting officer, respondent and parties, this shall include respective counsel for the parties, as soon as appropriate Notices of Appearance have been filed with the Board. PRELIMINARY PROCEDURES 1. Appeals, how taken. Notice of an appeal must be in writing, and the original, together with two copies, may be filed with the contracting officer from whose decision the appeal is taken. The notice of appeal must be mailed or otherwise filled within the time specified therefor in the contract or allowed by applicable provision of directive or law. 2. Notice of appeal, contents of. A notice of appeal should indicate that an appeal is thereby intended and should identify the contract (by number), the department and agency or bureau cognizant of the dispute, and the decision from which the appeal is taken. The notice of appeal should be signed personally by the appellant (the contractor making the appeal), or by an officer of the appellant corporation or member of the appellant firm, or by the contractor's duly authorized representative or attorney. The complaint referred to in Rule 6 may be filed with the notice of appeal, or the appellant may designate the notice of appeal as a complaint, if it otherwise fulfills the requirements of a complaint. 3. Forwarding of appeals (STATE). When a notice of appeal in any form has been received by the contracting officer, he shall endorse thereon the date of mailing (or date of receipt, if otherwise conveyed) and within 10 days shall forward said notice of appeal to the Board, with copies to the Supply and Transportation Services Division and the Legal Adviser of the Department of State. Following receipt by the Board of the original notice of an appeal (whether through the contracting officer or otherwise), the contractor, the contracting officer, the Supply and Transportation Services Division and the Legal Adviser of the Department of State will promptly be advised of its receipt, and the contractor will be furnished a copy of these rules. 4. Duties of the contracting officer (STATE). Following receipt of a notice of appeal, or advice that an appeal has been filed, the contracting officer shall promptly, and in any event within 30 days, compile and transmit to the Supply and Transportation Services Division copies of all documents pertinent to the appeal, including the following: (a) The findings of fact and the decision from which the appeal is taken, and the letter or letters or other documents of claim in response to which the decision was issued; (b) The contract, and pertinent plans, specifications, amendments, and change orders; (c) Correspondence between the parties and other data pertinent to the appeal; (d) Transcripts of any testimony taken during the course of proceedings, and affidavits or statements of any witnesses on the matter in dispute made prior to the filing of the notice of appeal with the Board; (e) Such additional information as may be considered material. The Supply and Transportation Services Division shall compile an appeal file from such documents, which file must contain the items enumerated in paragraphs (a)-(e) of this rule, and shall promptly, and in any event within 65 days after the appeal is docketed by the Board (except that this period shall not exceed 40 days if the con tracting officer is located, and necessary documentation is substantially available, within the United States) transmit the appeal file to the Board. The Supply and Transportation Services Division shall notify the appellant when it has transmitted the appeal file to the Board, will provide him with a listing of its contents, and will afford him an opportunity to examine the complete file at the office of the contracting officer or at the office of the Board for the purpose of satisfying himself as to the contents, and furnishing or suggesting any additional documentation deemed pertinent to the appeal. Following receipt of the foregoing file, as it may be augmented at the time of receipt, the Board will promptly advise the parties. 5. Dismissal for lack of jurisdiction. Any motion addressed to the jurisdiction of the Board shall be promptly filed. Hearing on the motion shall be afforded on application of either party, unless the Board determines that its decision on the motion will be deferred pending hearing on both the merits and the motion. The Board shall have the right at any time and on its own motion to raise the issue of its jurisdiction to proceed with a particular case, and shall do so by an appropriate order, affording the parties an opportunity to be heard thereon. 6. Pleadings. (a) Within 30 days after receipt of notice of docketing of the appeal, the appellant shall file with the Board an original and two copies of a complaint setting forth simple, concise, and direct statements of each of his claims, alleging the basis, with appropriate reference to contract provisions, for each claim, and the dollar amount claimed. This pleading shall fulfill the generally recognized requirements of a complaint, although no particular form or formality is required. Upon receipt thereof, the Recorder of the Board shall serve a copy upon the respondent. Should the complaint not be received within 30 days, appellant's claim and appeal may, if in the opinion of the Board the issues before the Board are sufficiently defined, be deemed to set forth his complaint and the respondent shall be so notified. (b) Within 30 days from receipt of said complaint, or the aforesaid notice from the Recorder of the Board, respondent shall prepare and file with the Board an original and two copies of an answer thereto, setting forth simple, concise, and direct statements of respondent's defenses to each claim asserted by appellant. This pleading shall fulfill the generally recognized requirements of an answer, and shall set forth any affirmative defenses or counterclaims, as appropriate. Upon receipt thereof, the Recorder shall serve a copy upon the appellant. Should the answer not be received within 30 days, the Board may, in its discretion, enter a general denial on behalf of the Government, and the appellant shall so be notified. 7. Amendments of pleadings or record. The Board upon its own initiative or upon ap |